This study examines the causes of time delays and cost overruns in a selection of thirty post-disaster reconstruction projects in Iraq. Although delay factors have been studied in many countries and contexts, little data exists from countries under the conditions characterizing Iraq during the last 10-15 years. A case study approach was used, with thirty construction projects of different types and sizes selected from the Baghdad region. Project data was gathered from a survey which was used to build statistical relationships between time and cost delay ratios and delay factors in post disaster projects. The most important delay factors identified were contractor failure, redesigning of designs/plans and change orders, security is

Huge yearly investments were made by organizations for the development and maintenance. However, it has been reported that most of the IT projects fails as it is delayed, over budget and discontinued quality. A systematic literature review (SLR) was conducted to identify the critical success factors (CSFs) for the IT projects. Nine (9) CSFs was identified from the SLR. An online survey was conducted among 103 respondents from developers and IT managers. The data was analyzed using the Statistical Package for Social Science (SPSS 22). The findings showed that the highest CSFs of IT projects is commitment and motivation. Project monitoring was found the lowest score ranked by respondents.

The main problem of this research is the delay of implementation of the investment plan projects for the period (2013-2016) and the weakness of the staff ability in the ministries and they don’t have the sufficient experience to carry out the implementation process.

Therefore, the research aims to evaluate the implementation of programs and projects of the investment plan in a manner consistent with the objectives set for them without any wasteful of efforts, time and money. And then identify the problems and obstacles to determine the deviations of the implementation of the specific for each sector according to the criteria of evaluation and the form of cost, quality, time and implementation.<

Green buildings are considered more efficient than traditional buildings due to the incorporated techniques and the multidisciplinary specializations required to comply with their specifications, in addition to the advanced commissioning, which undergoes before handing over the buildings to the owners to ensure requirements conformance. As a result, the appropriate selection of a project delivery system acts as the essential factor that affects the performance of the project. This research aims at building a system that helps to select the best method to implement green buildings. Through studying the recent research approaches in project delivery systems, the factors that affect the selection of the optimal implementation method fo

In this study, we investigate the run length properties for the EWMA charts with time - varying control limits, and fast initial Response (FIR), for monitoring the mean of a normal process with a known standard deviation , by using non - homogeneous markov chain approach.

The purpose of this research is to improve the organizational performance of the Oil Projects Company by adopting an approach to strategic change، and finding appropriate solutions to the problems facing the company. The researcher adopted in designing his research by conducting a survey of previous literature that dealt with approaches to strategic change، as the results of the survey showed that most researchers agree on the approach of renewal and modernization، Which formed a starting point for the researcher to identify the extent of the company's management interest in renewal and modernization to improve its level of performance، and the quality of the procedures followed on the ground that is related to

That the building of the national economy depends on the extent of the possibility of transition from the rent economy seeking to increase GDP (GDP1), and the tendency to manage projects with external sources of funding, or allow projects with foreign capital is a necessity. The strategic challenges faced by the economy in countries that have experience in investment projects have faced several factors internal and external for a period of time and not a few and the pressures and difficulties and failures have affected in one way or another on the development work in that country. On this basis, the stakeholders have a role to pay attention to the issue of the feasibility of the pattern of foreign investment in the investment environment

The research aims to identify the risks faced by projects and work on the administration, such as those risks by using professional Project Management System (Project Management Professional) by identifying those risks and their impact on the objectives of the project, if they occur and to provide appropriate responses to Ha.autam search application on the draft Law Faculty port by the General Mansour Construction Contracting company has been using a method personal interview with the heads of departments and project managers in the Al-Mansour and tools descriptive and quantitative analysis as was used (likelihood and impact of risk analysis, Ai_kaoa scheme Sbb- effect, analysis of probability and impact, risk matrix (probability