This essay aims to highlight the most important issues and difficulties facing implementing large projects that follow the turn-key method, considered one of the types of contractual methods in Iraq, especially for large and complex projects requiring speedy completion. The projects implemented in this way face delays and delays in completion, which led to the lack of benefit from the projects for which they were implemented, especially those affecting the lives of citizens within the health sector. The case study dealt with the construction of hospitals with multi-bed capacities within multiple governorates in Iraq, With large financial allocations within the federal budget of the Government of Iraq over several years. After conducting a descriptive statistical analysis of the data obtained through a field survey and interviews with individuals working in the construction sector with experience in their field. The most important 10 factors were identified from a list of 51 delay factors (distributed according to the questionnaire forms) with a high RII. These factors were related to the delay in the payment of the contractor's dues, the delay in processing materials, the issuance of new instructions and regulations, the delay in obtaining official approvals from the relevant authorities, Errors in designs or contracting documents, lack of cooperation between the contracting parties, and multiple spare orders for reasons belonging to the employer. The article also included the most important suggestions that contribute to reducing the delay in completing projects.
Objective(s): to assess the factors which are associated with the prolonged prehospital delay of patients with
acute myocardial infarction.
Methodology: A descriptive study was conducted at the Coronary Care unit (CCU) in Al-Yarmok Teaching
Hospital, Ibn AL-Nafis Hospital for Cardiovascular Diseases, AL-Kadumia Teaching Hospital, Baghdad Teaching
Hospital, and AL-Kindy Teaching Hospital during the period of the study from February 2
nd
, 2009 to October 30th
,
2009. A random sample of (160) paƟent who were admiƩed to the hospitals were selected one by one. A
questionnaire was constructed for the purpose of the study, which is comprised of four parts that include (1)
sociodemographic data; (2) prehospital d
Effective decision-making process is the basis for successfully solving any engineering problem. Many decisions taken in the construction projects differ in their nature due to the complex nature of the construction projects. One of the most crucial decisions that might result in numerous issues over the course of a construction project is the selection of the contractor. This study aims to use the ordinal priority approach (OPA) for the contractor selection process in the construction industry. The proposed model involves two computer programs; the first of these will be used to evaluate the decision-makers/experts in the construction projects, while the second will be used to formul
Huge yearly investments were made by organizations for the development and maintenance. However, it has been reported that most of the IT projects fails as it is delayed, over budget and discontinued quality. A systematic literature review (SLR) was conducted to identify the critical success factors (CSFs) for the IT projects. Nine (9) CSFs was identified from the SLR. An online survey was conducted among 103 respondents from developers and IT managers. The data was analyzed using the Statistical Package for Social Science (SPSS 22). The findings showed that the highest CSFs of IT projects is commitment and motivation. Project monitoring was found the lowest score ranked by respondents.
The construction industry in Iraq suffers from many problems, perhaps the most important of which is the delay in time and the increase in costs. Therefore, it was necessary to try to adopt a new methodology that would help in overcoming these problems. It was suggested to combine building information modeling with the agile management approach because this technique and methodology is modern and helps in reducing time and cost and improving quality. This paper aims to know the status of using Building Information Modeling (BIM) and Agile Project management (APM) in Iraq and to shed light on the merging of this integration, explaining the benefits, difficulties, and workflow practices, finding the most influencing factors on the tim
... Show MoreThe quality and cost of constructed buildings are heavily influenced by the performance of design/auditing consultants. Thus, selecting the right design consultant and design auditing consultants is of utmost importance and not an easy task for any construction client. so, the client should specify the efficiency criteria and assess the performance levels of the design and design auditing consultant firm. The study aims to identify the selection criteria of the design consultant in construction projects and also identify the selection criteria of the design auditing consultant for the construction projects by using the Delphi survey with applying the principal components analysis (PCA
Building Information Modeling (BIM) is extensively used in the construction industry due to its benefits throughout the Project Life Cycle (PLC). BIM can simulate buildings throughout PLC, detect and resolve problems, and improve building visualization that contributes to the representation of actual project details in the construction stage. BIM contributes to project management promotion by detecting problems that lead to conflicts, cost overruns, and time delays. This work aims to implement an effective BIM for the Iraqi construction projects’ life cycle. The methodology used is a literature review to collect the most important factors contributing to the success of BIM implementation, interview the team of the Cent
... Show MoreThe aim of this research work is to study the effect of stabilizing gypseous soil, which covers vast areas in the middle, west and south parts of Iraq, using liquid asphalt on its strength properties to be used as a base course layer replacing the traditional materials of coarse aggregate and broken stones which are scarce at economical prices and hauling distances. Gypseous soil brought from Al-Ramadi City, west of Iraq, with gypsum content of 66.65%, medium curing cutback asphalt (MC-30), and hydrated lime are used in this study. The conducted tests on untreated and treated gypseous soil with different percentages of medium curing cutback asphalt (MC-30), water, and lime were: unconfined compression strength, and one dimensional confine
... Show MoreThe aim of this research work is to study the effect of stabilizing gypseous soil, which covers
vast areas in the middle, west and south parts of Iraq, using liquid asphalt on its strength properties
to be used as a base course layer replacing the traditional materials of coarse aggregate and broken
stones which are scarce at economical prices and hauling distances.
Gypseous soil brought from Al-Ramadi City, west of Iraq, with gypsum content of 66.65%,
medium curing cutback asphalt (MC-30), and hydrated lime are used in this study.
The conducted tests on untreated and treated gypseous soil with different percentages of medium
curing cutback asphalt (MC-30), water, and lime were: unconfined compression strength, and o
Delays and disruption are a common issue in both community and personal building programs The problem exists all throughout the world, but it is particularly prevalent in Iraq, where millions of dollars are squandered each time as a outcome. Delays and interruptions may have serious consequences not just for Iraq's construction plans, but also for the country's economic and social status. While numerous studies have been conducted to investigate the factors driving delays and disruption in Iraqi construction projects, slight consideration has been given to by what means project management implements and approaches have affected the occurrence of project delays and disruption. After analyzing the crucial reasons for delays and instability in
... Show More