Preferred Language
Articles
/
joe-1847
Main Delay Factors of Implementation EPC Construction Projects in Iraq
...Show More Authors

This essay aims to highlight the most important issues and difficulties facing implementing large projects that follow the turn-key method, considered one of the types of contractual methods in Iraq, especially for large and complex projects requiring speedy completion. The projects implemented in this way face delays and delays in completion, which led to the lack of benefit from the projects for which they were implemented, especially those affecting the lives of citizens within the health sector. The case study dealt with the construction of hospitals with multi-bed capacities within multiple governorates in Iraq, With large financial allocations within the federal budget of the Government of Iraq over several years. After conducting a descriptive statistical analysis of the data obtained through a field survey and interviews with individuals working in the construction sector with experience in their field. The most important 10 factors were identified from a list of 51 delay factors (distributed according to the questionnaire forms) with a high RII. These factors were related to the delay in the payment of the contractor's dues, the delay in processing materials, the issuance of new instructions and regulations, the delay in obtaining official approvals from the relevant authorities, Errors in designs or contracting documents, lack of cooperation between the contracting parties, and multiple spare orders for reasons belonging to the employer. The article also included the most important suggestions that contribute to reducing the delay in completing projects.

Crossref
View Publication Preview PDF
Quick Preview PDF
Publication Date
Tue Mar 01 2016
Journal Name
Al-academy
Employing the elements of film construction in embodying the style cinematically: عامر الحديثي
...Show More Authors

The researcher concluded that it consists of several types of structures, where the intellectual structure related to the choice of the idea, its treatment, its effect, the choice of the topic, the way ideas are addressed and presented in the film, and then the dramatic structure of the film's characters, the formulation of its events, its dramatic composition, its temporal arrangement, the identification of the parties to the conflict and their management, then these are formulated. Visions and ideas through the visual and audio signal systems, which work to highlight the stylistic features in the character of the film director.

View Publication Preview PDF
Crossref
Publication Date
Mon May 28 2018
Journal Name
Iraqi Journal Of Science
Construction of a Robust Background Model for Moving Object Detection in Video Sequence
...Show More Authors

Background Subtraction (BGS) is one of the main techniques used for moving object detection which further utilized in video analysis, especially in video surveillance systems. Practically, acquiring a robust background (reference) image is a real challenge due to the dynamic change in the scene. Hence, a key point to BGS is background modeling, in which a model is built and repeatedly used to reconstruct the background image.

From N frames the proposed method store N pixels at location(x,y) in a buffer, then it classify pixel intensity values at that buffer using a proposed online clustering model based on the idea of relative  run length, the cluster center with the highest frequency will be adopted as the background pixel

... Show More
View Publication Preview PDF
Publication Date
Mon Jul 10 2023
Journal Name
Jordan Journal Of Civil Engineering
Factors Affecting Maintenance Practises in Iraq’s Hospital Buildings
...Show More Authors

A lack of adequate building maintenance is a significant obstacle faced by governmental hospitals. This paper evaluates factors that negatively impact building-maintenance practices in Iraq. A literature review was conducted to identify factors affecting maintenance. A list of 42 factors affecting hospital-buildings was collected from previous studies and tested using a structured questionnaire distributed to hospital-maintenance experts. During the data analysis, 76 valid questionnaires were used. Based on the respondents’ ratings, the relative-importance index (RII) was used to determine the level of importance of each factor. From the results, it was concluded that twelve factors affect maintenance practices in hospital buildin

... Show More
View Publication
Scopus (1)
Crossref (1)
Scopus Clarivate Crossref
Publication Date
Tue Jul 01 2014
Journal Name
Journal Of The Faculty Of Medicine Baghdad
Factors that predict mortality rate in biliary atresia
...Show More Authors

Background: B.A is a relatively rare obstructive condition of the bile ducts causing neonatal jaundice. The etiology is unknown but is the result of a progressive obliterative process of variable extent.  If not treated, B.A is fatal within the first 2 years of life.

Objectives: The aim of this study was to analyze & discuss the impact of many patients' factors on short-term outcome of patients with B.A who underwent Kasai operation in ou

Fac Med Baghdad

2014; Vol.56, No.2

Received: Feb. 2014

Accepted March. 2014

 

... Show More
View Publication Preview PDF
Crossref (1)
Crossref
Publication Date
Sat Dec 01 2018
Journal Name
Political Sciences Journal
Affecting factors in Yemeni - Russian Relations after 2011
...Show More Authors

Thethesis of theresearch is to deal with relations between Russia and Yemen after 2011.That relationwas significant in different fields, historic, economic, strategic and cultural ones. There are mutual interestsbetweenRussia and Yemen, especially with the economic development and growth in Russia as an important partner to Yemen.Their has to an a great deal of progress in different types of relations, where as they were only partner in military relations. The studywasclassifiedintoto three sections: the first section dealt with strategic importance of Yemen to Russia. And second section dealt withthe military factor between Russia and Yemen. While the third section dealt with the economic factor between Russia and Yemen. In addi

... Show More
View Publication Preview PDF
Crossref
Publication Date
Sun Jun 30 2013
Journal Name
Al-kindy College Medical Journal
Risk Factors for Recurrent Febrile Convulsions in Children
...Show More Authors

Background: Febrile convulsions are the most frequent type of seizures in children under 6 years of age. Significant percentage of these children will later suffer from recurrence of febrile convulsion.Objectives: To identify the main risk factors for recurrent febrile convulsions in children.Methods: we carried out a case control study involving 89 children those who experienced first attack of febrile convulsions and 92 children with recurrent attack of febrile convulsions. The study was conducted in Central Children Teaching Hospital, Baghdad during the period 2006- 2007. Results: Compared to children with first attack of febrile convulsion, children with recurrent seizures were younger at onset (4- 12m) (67% vs. 44%), mainly male (70

... Show More
View Publication Preview PDF
Publication Date
Mon May 02 2022
Journal Name
International Journal Of Research In Social Sciences & Humanities An International Open-access Peer Reviewed Referred Journal
Identity Construction and Social Structures in Sia Figiel’s Novel Where We Once Belonged
...Show More Authors

This article focuses on identity construction and social structures within the Sāmoan community as represented in Sia Figiel’s novel Where We Once Belonged. I argue that however the post/colonial Sāmoan identity is hybridized, the essence of the individual is still connected to Fa’a Sāmoa-the Sāmoan traditions and ways. However rapid are the colonial vicissitudes, the Sāmoan literature and lifestyle are developed to be a resistance platform. This resistance platform is dedicated not only to expose the colonial impact but also to assist the social and political reconstruction of post/colonial Samoa. To this end, this article studies identity construction, and the challenges that women face within Sāmoan social structures.

View Publication Preview PDF
Publication Date
Thu Mar 21 2024
Journal Name
Nauchi From
METAPHORICAL APPROACH TO DESCRIBING THE MAIN CHARACTER IN THE NOVEL OF THE RUSSIAN WRITER L. ULITSKAYA "SINCERELY YOUR SHURIK": MEANING AND INFLUENCE
...Show More Authors

The article reflects the results of the analysis of the use of metaphors as one of the main means used by Lyudmila Ulitskaya when writing the novel “Sincerely Yours Shurik” to form the image of the main hero in the novel. The main purpose of the article is to consider metaphors, which helped the author to form the image of the main character Shurik in the text space through the stages of his life path, closely related to the people around him, who is always happy to be useful (hence the title "Sincerely Yours"), among which the female images of his relatives, girlfriends and others stand out as a special layer in the narrative. And in the course of the study, the following tasks were solved: the metaphors that make up the image of the

... Show More
View Publication
Publication Date
Tue Dec 01 2020
Journal Name
Journal Of Economics And Administrative Sciences
Fuzzy Analytic Hierarchy Process FEAHP to Prioritize The Evaluation of The Main and Subsidiary Criteria in B2B Industrial Market Sectors – Applied Research
...Show More Authors

The research aims to define the main and subsidiary criteria for evaluating the industrial market sectors and proposing a model for arranging these criteria according to priority and knowing the highest criteria in terms of relative importance in the General Company for Automobile Trade and Machinery, and for the purpose of establishing this model, experiences in the concerned company were approved, and this study proposes a multi-criteria decision model According to the FEAHP, the expanded fuzzy hierarchical analysis method enables the commercial company to develop clear strategic policies on which the company’s management system depends on determining criteria for evaluating and selecting market sectors and making appropriate

... Show More
View Publication Preview PDF
Crossref
Publication Date
Thu Dec 08 2022
Journal Name
International Journal Of Interactive Mobile Technologies (ijim)
Implementation of RWP and Gauss Markov Mobility Model for Multi-UAV Networks in Search and Rescue Environment
...Show More Authors

Future generations of wireless networks are expected to heavily rely on unmanned aerial vehicles (UAVs). UAV networks have extraordinary features like high mobility, frequent topology change, tolerance to link failure, and extending the coverage area by adding external UAVs. UAV network provides several advantages for civilian, commercial, search and rescue applications. A realistic mobility model must be used to assess the dependability and effectiveness of UAV protocols and algorithms.  In this research paper, the performance of the Gauss Markov (GM) and Random Waypoint (RWP) mobility models in multi-UAV networks for a search and rescue scenario is analyzed and evaluated. Additionally, the two mobility models GM and RWP are descr

... Show More
View Publication
Crossref (6)
Crossref