This essay aims to highlight the most important issues and difficulties facing implementing large projects that follow the turn-key method, considered one of the types of contractual methods in Iraq, especially for large and complex projects requiring speedy completion. The projects implemented in this way face delays and delays in completion, which led to the lack of benefit from the projects for which they were implemented, especially those affecting the lives of citizens within the health sector. The case study dealt with the construction of hospitals with multi-bed capacities within multiple governorates in Iraq, With large financial allocations within the federal budget of the Government of Iraq over several years. After conducting a descriptive statistical analysis of the data obtained through a field survey and interviews with individuals working in the construction sector with experience in their field. The most important 10 factors were identified from a list of 51 delay factors (distributed according to the questionnaire forms) with a high RII. These factors were related to the delay in the payment of the contractor's dues, the delay in processing materials, the issuance of new instructions and regulations, the delay in obtaining official approvals from the relevant authorities, Errors in designs or contracting documents, lack of cooperation between the contracting parties, and multiple spare orders for reasons belonging to the employer. The article also included the most important suggestions that contribute to reducing the delay in completing projects.
The authentic traditional architecture proved that it is very convenient to the environmental and social regulations where it appeared and lasted for hundred of years.
This traditional architecture got the intelligence in providing thermal comfort for their occupants by the intelligent usage of the building materials and the intelligent planning and designs which took in consideration the climatic condition and the aerodynamics of the whole city as one ecological system starting from the cold breeze passing through its narrow streets till it enters the dwelling units and glides out through the wind catchers.
This architecture had been neglected and replaced by modern imported architecture which had collap
... Show MoreAbstract
Coronavirus has affected many people around the world and caused an increase in the number of hospitalized patients and deaths. The prediction factor may help the physician to classify whether the patient needs more medical attention to decrease mortality and worsening of symptoms. We aimed to study the possible relationship between C reactive protein level and the severity of symptoms and its effect on the prognosis of the disease. And determine patients who require closer respiratory monitoring and more aggressive supportive therapies to avoid poor prognosis. The data was gathered using medical record data, the patient's medical history, and the onset of symptoms, as well as a blood sample to test the
... Show MoreThe spectacular film is a type of feature films which has specific elements that contribute in increasing the aesthetics of the shape in its structure. The researcher started studying this type of films by researching the spectacular film concept, the history of its development, who are its most important stars and then tackling the Indian cinema represented by Bollywood, which is considered a school for this type of film. The researcher addressed the most important influential elements that entre in its production as well as studying these elements that contribute to building the shape including the configuration, movements of cameras, lenses, the lighting, colors, costumes etc. and what influence they have in forming a special aestheti
... Show MoreThe aim of the research is to determine the impact of evaluating the investment projects in the development and preparation of investment budgets prepared by the economic units, since the investment projects are of an important and vital nature of the economic units, because these projects include the length of time for preparation and implementation and the accompanying period of this risk and uncertainties as well as need To the many funds to complete the project , The process of evaluating the implemented projects, which have been prepared an investment budget previously will contribute to the extent of matching the estimated data with the actual results or deviations, which is a step to avoid these errors in future p
... Show MoreResearch is a study conducted by a researcher or a group of researchers to uncover ambiguity, complete a knowledge, or define a relationship, Solve a problem, or answer a question by carefully investigating the comprehensive and in-depth examination of the evidence and evidence related to this knowledge, revealing a relationship, or solving a problem, or answering a question, to be a systematic, In evidence and evidence that reveal facts and general rules, relationships or solutions, in addition to providing knowledge Human rights are verifiable, tested and confirmed. The university research (graduate research, master's thesis, doctoral dissertation) is the most important type of research, and it is supposed to be the best one, since it
... Show MoreThe area around the Suez Canal has been chosen particularly Sinai to implement the new Suez Canal project parallel to the original 72-km-long channel due to the importance of the commercial site of the Arab Republic of Egypt, competing with shipping lanes, to accommodate the increasing maritime traffic passing through the Suez canal, and to provide special services for trade world and reduce the economic cost of marine trip. The establishment of six tunnels for automobile and railway transport to Sinai The cost of the establishment of this new channel and the establishment of the tunnels about (2.8) billion, of which 4 billion cost of the new channel. Project implementation period is one year. The new proj
... Show MoreThis paper aims to review the intellectual to the most important thought leaders administrative and strategic They both (Henry Fayol and Michelle Porter), who forward a lot of ideas that have helped countries in the advancement and progress their economies , has been drawing literature theoretical common border in Contributions ( Fayol ) philosophical and between applications ( Porter ), which reversed strategies of the three ( the leadership of the cost, differentiation, and focus ), so browse search how to apply and use the principles of Fayol in the implementation of strategies competitiveness of Porter, and stems from a problem ( ( to what extent a reflection of the principles ( Fayol) fourteen strategies (Porter ) competitiv
... Show MorePriority of road maintenance can be viewed as a process influenced by decision-makers with varying decision-making power. Each decision-maker may have their view and judgment depending on their function and responsibilities. Therefore, determining the priority of road maintenance can be thought of as a process of MCDM. Regarding the priority of road maintenance, this is a difficult MCDM problem involving uncertainty, qualitative criteria, and possible causal relationships between choice criteria. This paper aims to examine the applicability of multiple MCDM techniques, which are used for assessing the priority of road maintenance, by adapting them to this sector. Priority of road maintenance problems subject to internal
... Show MoreThis research examines the impact of construction technology systems in contemporary architectural production through the study of the evolution in it systems, construction materials and methods of construction in addition to the digital revolution which provided possibilities of structural and architectural design in creating a distinct architectural product, as considered construction systems technology is the source of creativity in the architectural product, the research is assumed that the construction systems technology have achieved a structural innovation in production through the materials and methods of construction and digital design.
For Long time technology was connected to the