Preferred Language
Articles
/
joe-1847
Main Delay Factors of Implementation EPC Construction Projects in Iraq
...Show More Authors

This essay aims to highlight the most important issues and difficulties facing implementing large projects that follow the turn-key method, considered one of the types of contractual methods in Iraq, especially for large and complex projects requiring speedy completion. The projects implemented in this way face delays and delays in completion, which led to the lack of benefit from the projects for which they were implemented, especially those affecting the lives of citizens within the health sector. The case study dealt with the construction of hospitals with multi-bed capacities within multiple governorates in Iraq, With large financial allocations within the federal budget of the Government of Iraq over several years. After conducting a descriptive statistical analysis of the data obtained through a field survey and interviews with individuals working in the construction sector with experience in their field. The most important 10 factors were identified from a list of 51 delay factors (distributed according to the questionnaire forms) with a high RII. These factors were related to the delay in the payment of the contractor's dues, the delay in processing materials, the issuance of new instructions and regulations, the delay in obtaining official approvals from the relevant authorities, Errors in designs or contracting documents, lack of cooperation between the contracting parties, and multiple spare orders for reasons belonging to the employer. The article also included the most important suggestions that contribute to reducing the delay in completing projects.

Scopus Crossref
View Publication Preview PDF
Quick Preview PDF
Publication Date
Sat Jan 01 2011
Journal Name
Journal Of Water Resource And Protection
Seasonal Variations of Some Ecological Parameters in Tigris River Water at Baghdad Region, Iraq
...Show More Authors

View Publication
Crossref (36)
Crossref
Publication Date
Fri Dec 01 2017
Journal Name
Bulletin Of The Iraq Natural History Museum (p-issn: 1017-8678 , E-issn: 2311-9799)
NEW RECORD OF THE PARASITOID WASP MONODONTOMERUS OBSCURUS WESTWOOD, 1833 (HYMENOPTERA, TORYMIDAE) IN IRAQ
...Show More Authors

    This article reveals the first record of the parasitoid wasp, Monodontomerus obscurus Westwood (Hymenoptera, Torymidae) from Iraq.  A total of 27 specimens were emerged from mud nests of sphecoid wasp of Sceliphron sp. (Hymenoptera, Sphecidae), that collected from a wall at a residential garden in Dohuk province.  A short morphological description is presented.

View Publication Preview PDF
Scopus (4)
Crossref (1)
Scopus Crossref
Publication Date
Wed May 10 2017
Journal Name
Journal Of The College Of Languages (jcl)
Factores lingüísticos y extralingüísticos de la evolución semántica de los términos Linguistic and non-linguistic factors of the semantic evolution of terms
...Show More Authors

La disciplina sémantica siendo una rama de la lingüística y relacionada con los significados que residen detrás de los vocablos sería muy intereseante ser estudiada y investigada, sobre todo cuando tratamos de penetrarnos dentro de la evolución semántica y los motivos por los que se suceden estos cambios. Pues, es injusto dejar de dar una definición aclaratoria sobre esta disciplina y sus componentes.

El significado de los léxicos que se forma por un conjunto de semas o rasgos significativos mínimos. Sin embargo, no todos esos semas son igualmente intervenidos por los hablantes de una comunidad lingüística, sino que hay algunos de ellos que siempre están presentes, mientras que otros varían. Es decir, el significado

... Show More
View Publication Preview PDF
Publication Date
Sun Jul 26 2026
Journal Name
Journal Of Baghdad College Of Dentistry
The Effect of AcceleDent® Device on Both Gingival Health Condition and Levels of Salivary Interleukin-1-βeta and Tumor Necrosis Factors-Alpha in Patients under Fixed Orthodontic Treatment
...Show More Authors

Background: Orthodontic tooth movement is characterized by tissue reactions, which consist of an inflammatory response in periodontal ligament and followed by bone remodeling in the periodontium depending on the forces applied. These processes trigger the secretion of various proteins and enzymes into the saliva.The purpose of this study was to evaluate the activity of alkaline phosphatase (ALP) in saliva during orthodontic tooth movement using different magnitude of continuous orthodontic forces. Materials and Methods: Thirty orthodontic patients (12 males and 18 females) aged 17-23 years with class II division I malocclusion all requiring bilateral maxillary first premolar extractions were randomly divided into three groups according to t

... Show More
View Publication Preview PDF
Publication Date
Sat Jan 01 2022
Journal Name
Bild Law Journal
Law and its influential role for strategic leadership in managing security crises in Iraq
...Show More Authors

Scopus
Publication Date
Sun Jan 30 2022
Journal Name
Iraqi Journal Of Science
Haematological and Demographic Study in Children Infected with Enterobiasis in Al Diwaniyah Province, Iraq
...Show More Authors

     Enterobius vermicularis infection is considered as one of the important causes of anaemia and malnutrition among children. This topic has recently received an increased amount of attention.  The objective of this study is to evaluate the demographical, anthropometrical, nutritional, and  haematological status of E. vermicularis infection among children. This study was conducted in Al Diwaniyah province, south of Iraq, for the period of October 2020 to the end of January 2021. The study included 122 children from both genders (males, n= 61, and females, n=61) and their ages ranged between 1 and 14 years. Nutritional status, body mass index (BMI), BMI percentile, and weight- for- age Z score were evaluated for some particip

... Show More
Scopus (4)
Crossref (1)
Scopus Crossref
Publication Date
Sun Apr 17 2016
Journal Name
Al-academy
Expressionism in painting contemporary in Iraq Study features formalism: عبد الرزاق جبار رحيل الكناني
...Show More Authors

In the present research is marked (expressive drawing in contemporary Iraq, the study of morphological features) eating expressive as the direction of modern art in the drawing for the period before and after World Wars I and II. And follow the tracks. And in research and investigation about the origins and sources and characteristics of expressionist painting at adult patrons and art gatherings, and the extent of their impact in the drawing for contemporary Iraqi sixties and seventies generation (generation of professors) and down to the younger generation in the eighties of the last century. Over the nearly two decades of history of fine movement in Iraq, a period specified in the search within the limits of temporal boundaries, and by

... Show More
View Publication Preview PDF
Crossref
Publication Date
Mon Nov 03 2014
Journal Name
Iraqi Journal Of Physics
STVI calculating the changes in vegetable cover for a vegetated environment in west Iraq
...Show More Authors

Publication Date
Sun Jul 26 2026
Journal Name
Modern Sport
Time out in basketball and it effect on playing for excellent degrees in Iraq
...Show More Authors

The value of time out as a time not count of official time form the game like four periods and extra time also it considered a great interest if used well thru the game , the importance of this problem is not using well the time out and when the coach ask for time out and how to invest this time legally to make good results also there is no observing system as the researcher see gives the reality image that the coach is successful lead the game when he takes time out . The goals of research that knowing on numbers of time out for excellent teams in Iraq (first &second) stages and putting special inventory reverse reality of asking time out (positive &negative) on playing basketball , the hypothesis of research that tell the time out effect

... Show More
View Publication Preview PDF
Publication Date
Sat Dec 01 2018
Journal Name
Journal Of Economics And Administrative Sciences
International Auditing Standards and their role in rationalizing the auditor's personal judgment in Iraq"
...Show More Authors

The impact of the auditor's personal judgment starts from the beginning of the audit process to the formation of the final opinion and the issuance of the report, and because of the possibility of bias in the auditor's judgment for various reasons that may relate to the auditor himself or the circumstances surrounding it, which requires assessing the current reality of the auditor's personal judgments In the local environment and determining their determinations. To clarify the concept and determinants of the auditor's personal judgments when implementing the audit work, prepare the report and determine the role of the international auditing standards in rationalizing the auditor's personal judgment when conducti

... Show More
View Publication Preview PDF
Crossref