This study examines the causes of time delays and cost overruns in a selection of thirty post-disaster reconstruction projects in Iraq. Although delay factors have been studied in many countries and contexts, little data exists from countries under the conditions characterizing Iraq during the last 10-15 years. A case study approach was used, with thirty construction projects of different types and sizes selected from the Baghdad region. Project data was gathered from a survey which was used to build statistical relationships between time and cost delay ratios and delay factors in post disaster projects. The most important delay factors identified were contractor failure, redesigning of designs/plans and change orders, security issues, selection of low-price bids, weather factors, and owner failures. Some of these are in line with findings from similar studies in other countries and regions, but some are unique to the Iraqi project sample, such as security issues and low-price bid selection. While many studies have examined factors causing delays and cost overruns, this study offers unique insights into factors that need to be considered when implementing projects for post disaster emergency reconstruction in areas impacted by wars and terrorism.
A recently reported Nile red (NR) dye conjugated with benzothiadiazole species paves the way for the development of novel organic-based sensitizers used in solar cells whose structures are susceptible to modifications. Thus, six novel NR structures were derived from two previously developed structures in laboratories. In this study, density functional theory (DFT) calculations and time-dependent DFT (TD-DFT) were used to determine the optoelectronic properties of the NR-derived moieties such as absorption spectra. Various linkers were investigated in an attempt to understand the impact of π-linkers on the optoelectronic properties. According to the findings, the presence of furan species led to the planarity of the molecule and a reduction
... Show MoreThe research investigates the political effect and its directions on the architectural thoughts and its achievements and how can this political system affect all fields of life in communities including architectural urban design. The problem of the research lies in the ambiguity effects of the ideological national directions of the Nazi Party on the architecture and urban design of the city of Berlin, then determining the aims of the research to discuss the concepts of politics and architecture and their relation to the way of thinking that plays a role in the process of design that works on property and achieving the suitable urban environments for those communities. After that, the Nazi's party's thought would be studied and analyzed,
... Show MoreThis research aims to study the mechanism of application of international specification requirements (ISO 9001: 2015) at the Iraqi Center- Korean Vocational Training return to vocational training department at the Ministry of Labour and Social Affairs for the purpose of preparing and creating the center to get a certificate of conformity with the requirements of the standard (ISO 9001: 2015) that would elevate the level of performance and services provided in the respondent Center after it is identified and the study of the reality of the quality management system by identifying strengths and weaknesses in the system to diagnose the gap and find ways to address that gap, and adopted the researchers the case study method to conduc
... Show MoreThe research examines the mechanism of application of )ISO 21001: 2018( in the Energy Branch- Electromechanical Engineering at the University of Technology to achieve the quality of the educational service to prepare the branch to obtain the certificate of conformity with the requirements of) ISO 21001: 2018(, the necessary data were collected Depending on the (CHEKLIST) of (ISO 21001: 2018), field interviews and records of the concerned department, The researchers reached a number of results, the most prominent of which was the adoption of high quality leadership leaders and their willingness to implement the standard requirements, The university has a basic structure that qualifies it to implement the international standard, as
... Show MoreThe aim of the research is to identify the impact of the dimensions of the European Excellence Model in evaluating the performance of the bank of the research sample, as well as to interpret which dimensions are more important to the banks of the research sample. Based on the dimensions of this model, the United Bank for Investment and Finance has chosen a research community, and has met with officials of the United Bank for Investment and Finance at various administrative levels to measure the practices of excellence management in the European model, and the analytical approach has been the case study and the construction of the checklist as a tool to collect information. The research has reached the most important results There is a discr
... Show MoreThe research starts from studying the contractual budget, which is one of the modern trends in preparing public budgets, both operational and capital, in addition to meeting the requirements of the global trend to achieve sustainable growth in all fields, whether financial or non-financial, and tools for the contractual budget have been identified (participation contracts, planning Implementation, monitoring) and studying its impact in supporting sustainable development through its dimensions (economic, social, and environmental). The method of the questionnaire was adopted as a main tool in collecting information on research variables and distributing it to a sample of (70) individuals who dictate positions of professional respo
... Show MoreAn experimental study was performed to estimate the forced convection heat transfer performance and the pressure drop of a single layer graphene (GNPs) based DI-water nanofluid in a circular tube under a laminar flow and a uniform heat flux boundary conditions. The viscosity and thermal conductivity of nanofluid at weight concentrations of (0.1 to 1 wt%) were measured. The effects of the velocity of flow, heat flux and nanoparticle weight concentrations on the enhancement of the heat transfer are examined. The Nusselt number of the GNPs nanofluid was enhanced as the heat flux and the velocity of flow rate increased, and the maximum Nusselt number ratio (Nu nanofluid/ Nu base fluid) and thermal performance factor
... Show MoreThe complexes of Schiff base (6-[Hydroxy - benzylidene)-amino]-pyrimidine-2,4-diol ) (L) with Mn(II), Fe(II), Co(II) and Ni(II) were prepared. The Schiff base and complexes have been characterized by FT-IR, 1H-NMR, UV-Vis, LC-mass spectra, magnetic moment, elemental microanalyses (C.H.N.), chloride containing, atomic absorption and molar conductance.
The Schiff base, metal salts and complexes were also screened for their bioactivity such as antibacterial and antifungal.
Key words:Jasminumsambac, Volatile oil, Antioxidant.